Hong Kong Disneyland – Grizzly Gulch
- Client: KHSS International
- Value: HK$12 million / US$1 million
About this Project
The Grizzly Gulch attraction is a 1100m steel rail roller coaster with a mining theme, the centre piece of the Hong Kong Disneyland Frontier Land. CDC advised the subcontractor for the faux rock works with regard to a dispute arising out of the construction. The subcontract was delayed by resequencing of work and technical discrepancies. CDC undertook claim preparation, provided contractual and dispute advice and assisted the contractor and legal teams with preparation for arbitration proceedings. CDC also provided delay analysis for the project. The dispute was settled prior to commencement of pleadings.
More Case Studies
The Hari Hotel, Wanchai, Hong Kong
CDC were engaged to assist with the strengthening and pursuit of EoT claims on the project. The submitted EOT claims were reviewed and an updated assessment of the critical path was prepared following completion of the works.
Power Transmission Platform, Hinkley Point C
CDC advised the contractor on a claim for delayed access to the Works and prepared a presentation in support of negotiations.
I-405 Improvement, Orange County, California
CDC undertook an independent review of expected claim revenue on the project. This involved reviewing claim documentation and cost information and verifying the estimated recovery in line with the contract terms.